Skip to content
Aperlena
Free alerts

TED - Tenders Electronic Daily (Publications Office of the EU) verified 4 hours ago Contract notice

Belgique - Travaux de construction - Marché de travaux ayant pour objet la construction d'une maison de repos (Lot 1 - Architecture (lot PILOTE) - Lot 2 - HVAC (lot piloté) - Lot 3 - Électricité (lot piloté) - Lot 4 - Cuisine (lot piloté))

Open Belgium Prov. Hainaut Construction work

Buyer ASSOCIATION INTERCOMMUNALE GÉNÉRATIONS THIÉRACHE SC

24 days left

Key facts

Closes
10:00 (UTC+1)
Procedure
Open procedure
  1. Published
  2. Today
  3. Deadline open for 30 days
  4. Awarded pending

Bidding window

30 days from publication to deadline

Usual length

Notices of this kind (Belgium, open procedure, above the EU threshold) give a median of 30 days, half of them between 17 and 37 days, based on 10,347 notices of the last two years.

View the official notice Watch this tender
Add to calendar

If the deadline moves or the notice is corrected, we email you. Log in

Description

Le présent marché est un marché de travaux qui comprend l’exécution des travaux suivants (description générale des travaux à réaliser) : Marché de travaux en 4 lots ayant pour objet la construction d'une maison de repos : - Lot 1 - Architecture - Lot 2 - HVAC - Lot 3 - Électricité - Lot 4 - Cuisine. Les travaux décrits ci-dessus ne sont pas exhaustifs. Le détail des travaux est repris dans les clauses techniques et le métré récapitulatif annexé au cahier spécial des charges. Il est expressément stipulé que l’entrepreneur doit exécuter les travaux suivant les règles de l’art. Les lieux d’exécution sont définis comme suit (voir également plans et métrés) : Rue de Beauwelz, n°13 à 6590 MOMIGNIES Code CPV : - Lot 1 - Architecture : o 45000000-7 - Travaux de construction o 45400000-1 - Travaux de parachèvement de bâtiment - Lot 2 - HVAC : o 45232460-4 - Travaux d'installations sanitaires o 45331000-6 - Travaux d'installation de matériel de chauffage, de ventilation et de climatisation - Lot 3 - Électricité : o 45315300-1 - Installations d'alimentation électrique - Lot 4 - Cuisine : o 45421151-7 - Installation de cuisines équipées Numéro de marché : CSC n°58600 - Marché n°2017/116-2017/135 Tous les matériaux à mettre en œuvre dans le présent marché sont neufs et sont à fournir par l’entrepreneur, à moins que le cahier spécial des charges ne le précise autrement. Dans le cadre du présent marché, l’adjudicateur entend lutter contre le dumping social et la fraude sociale (Voy. A2.91). En cas d’application au titre A2.6 Clauses sociales d’une clause sociale flexible : dans le cadre du présent marché, l’adjudicateur souhaite favoriser l'insertion professionnelle en réalisant un effort de formation, d’insertion ou d’intégration socioprofessionnelle. Autres clauses particulières prévues dans le cadre de ce marché : - Mission de pilotage : Voy. A2.94. Le marché repris dans le présent cahier des charges est financé par l’AVIQ. Des obligations en matière de respect des délais seront à prendre en compte lors de l’exécution de ce chantier. L’attribution du marché doit avoir lieu avant le 31 décembre 2027 et toutes les phases doivent avoir débuté avant le 31 décembre 2030. A cet effet, il est prévu une pénalité spéciale par jour de retard en complément de l’article 45 de l’A.R. du 14 janvier 2013 (voir point A4.72. Pénalités). Lot 1 - Architecture; Lot 2 - HVAC; Lot 3 - Électricité; Lot 4 - Cuisine

Bid or no-bid?

Six questions before you commit a team. Under each one, what the register holds on it. The answers are yours.

  1. In your favour:

    Do we meet every eligibility criterion?

    Open procedure: any interested supplier may submit a bid.

    Above the EU threshold: open to companies from any EU country.

  2. Your call:

    Can we deliver this with the team we have?

    The register holds nothing on this. The official documents will.

  3. Your call:

    Do we have two comparable references?

    Comparable work is in Construction work.

  4. In your favour:

    Is the deadline realistic for a proper offer?

    24 days left, 19 of them working days.

  5. Your call:

    Is there a margin at the likely winning price?

    In this country this kind of contract is usually awarded for between €3.3M and €11.8M.

  6. Your call:

    Do we know this buyer?

    The register holds nothing on this. The official documents will.

Can I bid?

  • Open procedure: any interested supplier may submit a bid. Above the EU threshold: open to companies from any EU country.
  • The notice is written in French.
  • Certificates from another EU country? Check the equivalents on eCertis

Official source

Source: TED - Tenders Electronic Daily (Publications Office of the EU)

Always verify details on the official notice.

Report an error in this notice

Last verified against TED - Tenders Electronic Daily (Publications Office of the EU) 4 hours ago

View the official notice

What this market pays

The buyer has too few awards of its own in this sector, so this is the range of the last 460 awards for Construction work in Belgium.

Median award
€7.0M
Middle half of past awards
€3.3M to €11.8M

TED - Tenders Electronic Daily (Publications Office of the EU) publishes no value for this notice, so it has no mark on the scale. The official documents may state one.

Award values as published by the official sources. Use them as a guide, not a rule: scope, lots and duration differ between contracts.

The buyer

Full buyer profile

ASSOCIATION INTERCOMMUNALE GÉNÉRATIONS THIÉRACHE SC

Belgium

This buyer has no award history in this sector yet. Usual winners, Construction work - Belgium

Company Wins Total awarded Last win
WILLEMEN INFRA 15 €95.8M Sep 2026
STADSBADER 9 €88.8M Sep 2026
Colas Noord 8 €58.8M Aug 2026
Galère 6 €61.3M Sep 2026
RECON BOUW 6 €30.6M Sep 2026

Based on 576 awards with a linked company profile over the last 2 years.

Market context

TED - Tenders Electronic Daily (Publications Office of the EU) publishes no value for this notice, so it cannot be placed among the open notices of its sector. The official documents may state one.

open now in Construction work
28,901
median open notice
€812,445

Who wins in this market

Many suppliers

Belgium · Construction work

different companies won awards here
429
of the awards went to the three most frequent winners
6%
buyers awarded contracts here
269

Based on 576 awards with a named winner over the last 3 years. Counted by award, not by value, because lot and framework amounts are not comparable. Concentrated means the three most frequent winners took 65% or more of the awards; many suppliers, under 35% with at least ten different winners.

Similar tenders

Open now

Awarded before

Never miss a tender like this

1,299 new notices in Construction work in Belgium in the last 7 days. Get an email when new ones appear. Free.

Set up my alert

24 days left

Open notice

Keyboard shortcuts

Read a list without reaching for the mouse. The shortcuts stay quiet while you type in a field.

j
Next result
k
Previous result
Enter
Open the result
n
Next page
p
Previous page
c
Compare this result
s
Shortlist this result
o
Open the result in a new tab
x
Set this result aside
/
Search from any page
Ctrl K
Search from any page
?
Show these shortcuts
Esc
Close

Start from a question

Browse by sector

Index

Close
Log in

Language